Window and Storefront System Replacement Project - County Courthouse, Beaufort, NC
- Owner Reference
- ITB # 05062026
- Bid Date
- May 27, 2026 at 01:00pm
- Pre-Bid
- Scheduled, Optional - 5/11/2026 @ 11:00am @ (for location please or )
- Owner
- County of Carteret, NC
- DBE Goal
- 10%
- Trades
- *General Building Contractor GBC: Building Construction, Enclosed Structures; Opportunities for Subcontractors
- Phase
- Renovation, Remodel, Improvements, Upgrades
- Duration
- 200 days
Description
General Scope of Work Replacement of 166 existing windows with fixed pane units. Replacement of three (3) existing single storefront doors with sidelights. Replacement of the existing two (2) story storefront system on the northside of the breezeway. Replacement of the existing storefront system into the Courthouse courtyard. Replacement of two (2) 2-story fixed pane windows into Courthouse courtyard. Replacement of 2-story fixed pane windows on west wall. The Contractor shall abide by the installation of the window and door requirements provided by the manufacturer. The Contractor shall coordinate security termination for badge access doors with the County POC. Additional Provisions The Contractor shall field verify all measurements and material quantities. The Contractor shall provide a detailed breakdown on company letterhead with this ITB. Any damages caused by the Contractor shall be repaired or replaced at the Contractors expense, subject to the Countys discretion. Existing interior conditions shall be returned to their pre-construction conditions at the expense and responsibility of the Contractor. The awarded Contractor shall execute a contract with the County and comply with all Terms and Conditions and the Agreement for Services. The Contractor shall obtain the required permits, if required, give all notices to the County POC (including a copy of any permits), and comply with all laws, ordinances, codes, rules and regulations bearing on the conduct of the work. Permits shall be posted onsite at project location. No time extensions shall be granted or financial consideration given to the Contractor for time or monies lost due to violations of any such ordinance, code, law or regulations that may occur.
Bonds required.
Contact
- or to view contact name.
- or to view phone number.
- or to view email address.
Plans & Specifications
or to view plans and specification details.
CBS ID: 824209 | Published 5/15/2026 on Construction Bid Source
DISCLAIMER: The bid notifications listed on Construction Bid Source are compiled from various sources and updated daily. It is the responsibility of each user, whether browsing publicly or logged in, to contact the project owner directly for the purpose of bidding and obtaining additional project details. Construction Bid Source does not assume any responsibility for omissions or errors in the information provided.
Documents
DBE/HUB Outreach Ads
This project requires a Good Faith Effort (GFE) outreach. For information regarding Construction Bid Source performing a GFE for you, please call us toll free at (888) 988-1208