Carteret County Government is seeking competitive proposals for the installation of a new Cellular-Enabled Fire Alarm System as well as an alternate proposal for monitoring, maintenance, repair and inspections for Carteret County Governments Leon Mann Jr. Enrichment Center located at 3820 Galantis Drive, Morehead City, NC 28557.
Post Date: 05/29/2026Bid Date:06/10/2026Trades: Fire Protection: Fire Alarm, Smoke Detection & Fire Suppression Contractor, Fire Extinguishers, Pumps, Hydrants & Inspections
The selected contractor shall be responsible for furnishing equipment and providing hauling services for solid waste and recyclable materials collected at twelve (12) convenience sites and various County building locations. In addition, the contractor shall provide staffing and fully operate these convenience sites, which serve the unincorporated areas of Carteret County.
General Scope of Work Replacement of 166 existing windows with fixed pane units. Replacement of three (3) existing single storefront doors with sidelights. Replacement of the existing two (2) story storefront system on the northside of the breezeway. Replacement of the existing storefront system into the Courthouse courtyard. Replacement of two (2) 2-story fixed pane windows into Courthouse courtyard. Replacement of 2-story fixed pane windows on west wall. The Contractor shall abide by the installation of the window and door requirements provided by the manufacturer. The Contractor shall coordinate security termination for badge access doors with the County POC. Additional Provisions The Contractor shall field verify all measurements and material quantities. The Contractor shall provide a detailed breakdown on company letterhead with this ITB. Any damages caused by the Contractor shall be repaired or replaced at the Contractors expense, subject to the Countys discretion. Existing interior conditions shall be returned to their pre-construction conditions at the expense and responsibility of the Contractor. The awarded Contractor shall execute a contract with the County and comply with all Terms and Conditions and the Agreement for Services. The Contractor shall obtain the required permits, if required, give all notices to the County POC (including a copy of any permits), and comply with all laws, ordinances, codes, rules and regulations bearing on the conduct of the work. Permits shall be posted onsite at project location. No time extensions shall be granted or financial consideration given to the Contractor for time or monies lost due to violations of any such ordinance, code, law or regulations that may occur.
Post Date: 05/15/2026Bid Date:05/27/2026Trades: *General Building Contractor GBC: Building Construction, Enclosed Structures; Opportunities for Subcontractors
Carteret County Government is seeking competitive proposals from qualified contractors for the removal and complete replacement of three (3) sets of existing historic exterior wood door assemblies at the Courthouse Complex located at 302 Courthouse Square, Beaufort, NC 28516.
Post Date: 05/15/2026Bid Date:05/28/2026Trades: *General Building Contractor GBC: Building Construction, Enclosed Structures; Opportunities for Subcontractors
Carteret County Government is seeking competitive proposals to replace exterior door and frame systems at the Leon Mann Jr. Enrichment Center located at 3820 Galantis Drive, Morehead City, NC 28557.
Post Date: 05/15/2026Bid Date:05/28/2026Trades: *General Building Contractor GBC: Building Construction, Enclosed Structures; Opportunities for Subcontractors